Welcome to Construction Fusion USA, LLC (“Company”). These Terms of Service (“Terms”) govern your use of our website and our construction administration and Owner’s Representative services.
By accessing our website or engaging our services, you agree to comply with and be bound by these Terms. If you have any questions about these Terms, please contact us. all our clients will be informed in case the terms of services has any change.
Scope of Services
The Company provides construction administration and Owner’s Representative services. Our role is limited to project management, administrative support, and coordinating with clients and third-party contractors.
We do not provide licensed architectural, engineering, construction, real estate, brokerage, financial, or investment advisory services. Our services are advisory and administrative in nature, intended to support clients in managing their construction projects.
Limitations and Disclaimers
The Company does not hold licenses in architecture, engineering, construction, real estate, brokerage, finance, or investment. We do not perform or offer any services that require such licenses under Florida state or federal law.
No Guarantee of Outcomes: We do not guarantee any specific outcome, return on investment, or financial gain from any construction project. The Company is not responsible for any financial gains or losses incurred by the client concerning the project.
Market Fluctuations: Market costs, material prices, and contractor fees can fluctuate. The Company is not responsible for managing or predicting such changes and is not liable for any increased costs or financial losses due to these market factors.
No Financial or Investment Advice: The Company does not provide financial, real estate investment, or other advisory services. All financial decisions are the sole responsibility of the client, and we recommend consulting licensed professionals for specific advice.
Client Responsibilities
The client is solely responsible for hiring licensed professionals (e.g., architects, engineers, general contractors) as required for the project. The Company may facilitate communication among these professionals but is not liable for their work quality, regulatory compliance, or contract fulfillment.
Clients must ensure that any third-party contractors comply with all applicable laws, building codes, and safety regulations. The Company does not oversee or manage compliance with these requirements.
Third-Party Relationships
The Company may assist in identifying third-party professionals for the client’s consideration; however, the final selection, contracting, and payment of these professionals are solely the client’s responsibility.
The Company does not warrant the quality, expertise, or reliability of any third-party contractors and is not liable for their actions, errors, or omissions.
Fees and Payment
Fees for our services are outlined in the agreement with each client and are based on project milestones, hourly rates, or other agreed-upon terms.
Payment terms, including deposits, progress payments, and final payments, are specified in each individual agreement. Late payments may incur additional fees as outlined in the service agreement.
Indemnification
The client agrees to indemnify, defend, and hold the Company harmless from any claims, damages, losses, or liabilities, including attorney fees, arising from any construction project for which the Company provides administrative or coordination services.
This indemnification includes claims resulting from actions, errors, or omissions by third-party contractors or professionals involved in the project.
Limitations of Liability
The Company shall not be held liable for any direct, indirect, incidental, or consequential damages arising from the client’s use of our services or reliance on any information provided by the Company.
We are not responsible for construction defects, compliance issues, delays, or increased costs related to the construction project. All construction decisions, outcomes, and compliance with local regulations are the responsibility of the licensed professionals hired by the client.
Confidentiality and Privacy
We respect your privacy and are committed to protecting your personal information. Please review our Privacy Policy
for details on how we handle your information.
The Company will maintain the confidentiality of client information as required by law and will only share information with third parties involved in the project as authorized by the client.
Dispute Resolution
In the event of a dispute between the client and the Company, both parties agree to attempt mediation before pursuing legal action. Mediation costs will be shared equally by both parties.
If mediation fails, disputes will be resolved in the courts of Palm Beach County, FL, and the client agrees to submit to the jurisdiction of these courts.
Modifications to Terms
The Company reserves the right to modify these Terms at any time. Changes will be effective immediately upon posting on our website, and continued use of our services indicates acceptance of the revised Terms.
Governing Law
These Terms are governed by the laws of Palm Beach County, FL. Any legal action arising from or related to these Terms or the services provided by the Company shall be brought in the appropriate court in Palm Beach County, FL.
Contact Information
For any questions or concerns about these Terms of Services, please contact us at:
928 S Dixie Hwy, Unit #511 – Lantana, FL 33462
contact@constructionfusionusa.com
1-718-578-1167

By engaging our services, you acknowledge and agree to these Terms.